Legal

Terms of Service

Last updated: June 1, 2025

These terms govern your engagement with Creative Detroit Placemakers ("CDP," "we," "our," or "us") for interior design services. By engaging our services, you agree to these terms.

Service Agreements

All design projects begin with a signed project agreement outlining the scope of work, deliverables, timeline, and fees. Work does not commence until a signed agreement and initial deposit are received.

Payment Terms

Payment schedules vary by project type and scope:

  • Build Design projects: Typically structured as a deposit at signing, milestone payments during the project, and a final payment upon completion.
  • Consultations (On-Site and Virtual): Payment is due at the time of booking or prior to the session.
  • Large Room Design: Payment schedule outlined in the project agreement, typically split into phases.

All payments are due by the dates specified in your project agreement. Late payments may result in project delays.

Revisions

Each service tier includes a specified number of revision rounds as outlined in your project agreement. Revisions beyond the included rounds are billed at our standard hourly rate. Substantial scope changes may require a revised agreement.

Delivery Timeline

Project timelines are estimated and provided in good faith. Timelines may be affected by factors outside our control, including vendor lead times, contractor availability, material shortages, or client approval delays. We communicate proactively about any changes to agreed timelines.

Client Responsibilities

To ensure project success, clients agree to:

  • Provide timely feedback and approvals at each project milestone
  • Ensure site access for consultations, measurements, and installation
  • Communicate budget parameters and any constraints clearly
  • Make payments on schedule as outlined in the project agreement

Intellectual Property

All design concepts, drawings, mood boards, and materials created by CDP remain our intellectual property until full payment is received. Upon final payment, the client receives full rights to use the delivered design materials for the specified project.

Photography and Portfolio Use

We reserve the right to photograph completed projects for portfolio and marketing purposes, with reasonable notice to the client. Clients may opt out of this by notifying us in writing prior to project completion.

Cancellation Policy

Cancellation terms are specified in each project agreement. In general, the initial deposit is non-refundable as it covers discovery and planning work. For ongoing projects, a cancellation fee may apply based on work completed to date.

Limitation of Liability

Creative Detroit Placemakers is not liable for delays or damages caused by third-party contractors, vendors, or suppliers. Our liability is limited to the fees paid for our design services.

Governing Law

These terms are governed by the laws of the State of Michigan. Any disputes shall be resolved in the courts of Wayne County, Michigan.

Contact

For questions about these terms, contact us at: